|LIEN LAWS BY STATE
|DISCLAIMER: TRADITION SOFTWARE, INC. makes no warrant, express or implied for the use of this website. In no event shall TRADITION SOFTWARE, INC. be liable to anyone for any problem, claim or loss arising out of the use of TraditionSoftware.com. TRADITION SOFTWARE, INC. is not engaged in practicing law nor does TRADITION SOFTWARE, INC. provide legal advice in the state of Washington.|
REVISED CODE OF WASHINGTON
TITLE 60 RCW LIENS
CHAPTER 60.04 RCW MECHANICS’ AND MATERIALMEN’S LIENS
60.04.021 Lien Authorized
60.04.035 Acts of Coercion-Application of Chapter 19.86 RCW
60.04.041 Contractor Registration
60.04.051 Property Subject to Lien
60.04.061 Priority of Lien
60.04.071 Release of Lien Rights
60.04.081 Frivolous Claim-Procedure
60.04.091 Recording-Time-Contents of Lien
60.04.101 Separate Residential Units-Time for Filing
60.04.131 Claims-Designation of Amount Due
60.04.141 Lien-Duration-Procedural Limitations
60.04.151 Rights of Owner-Recovery Options
60.04.161 bond In Lieu of Claim
60.04.181 Rank of Lien-Application of Proceeds-Attorneys’ Fees
60.04.190 Destruction or Concealment of Property-Removal from Premises-Penalty
60.04.191 Effect of Note-Personal Action Preserved
60.04.201 Material Exempt from Process-Exception
60.04.211 Lien-Effect on Community Interest
60.04.221 Notice to Lender-Withholding of Funds
60.04.226 Financial Encumbrances-Priorities
60.04.230 Construction Projects-Notice to be Posted by Prime Contractor-Penalty
60.04.250 Informational Materials on Construction Lien Laws-Master Documents
60.04.255 Informational Materials on Construction Lien Laws-Copies-Liability
60.04.261 Availability of Information
60.04.900 Liberal Construction-1991 c 281
60.04.901 Captions Not Law-1991 c 281
60.04.902 Effective Date, Application-1991 c 281
60.04.903 Effective Date-1992 c 126
60.04.904 Application of Chapter 281, Laws of 1991, To Actions Pending as of June 1, 1992-1993 c 357
REVISED CODE OF WASHINGTON
TITLE 60 RCW LIENS
CHAPTER 60.04 RCW MECHANICS’ AND MATERIALMEN’S LIENS
RCW 60.04.011 Definitions
Unless the context requires otherwise, the definitions in this section apply throughout this chapter.
(a) Funds to acquire real property;
(b) Funds to pay interest, insurance premiums, lease deposits, taxes, assessments, or prior encumbrances;
(c) Funds to pay loan, commitment, title, legal, closing, recording, or appraisal fees;
(d) Funds to pay other customary fees, which pursuant to agreement with the owner or borrower are to be paid by the lender from time to time;
(e) Funds to acquire personal property for which the potential lien claimant may not claim a lien pursuant to this chapter.
RCW 60.04.021 Lien Authorized
Except as provided in RCW 60.04.031, any person furnishing labor, professional services, materials, or equipment for the improvement of real property shall have a lien upon the improvement for the contract price of labor, professional services, materials, or equipment furnished at the instance of the owner, or the agent or construction agent of the owner.
RCW 60.04.031 Notices-Exceptions
(1) Except as otherwise provided in this section, every person furnishing professional services, materials, or equipment for the improvement of real property shall give the owner or reputed owner notice in writing of the right to claim a lien. If the prime contractor is in compliance with the requirements of RCW 19.27.095, 60.04.230, and 60.04.261, this notice shall also be given to the prime contractor as described in this subsection unless the potential lien claimant has contracted directly with the prime contractor. The notice may be given at any time but only protects the right to claim a lien for professional services, materials, or equipment supplied after the date which is sixty days before:
(a) Mailing the notice by certified or registered mail to the owner or reputed owner; or
(b) Delivering or serving the notice personally upon the owner or reputed owner and obtaining evidence of delivery in the form of a receipt or other acknowledgement signed by the owner or reputed owner or an affidavit of service.
In the case of new construction of a single-family residence, the notice of a right to claim a lien may be given at any time but only protects the right to claim a lien for professional services, materials, or equipment supplied after a date which is ten days before the notice is given as described in this subsection.
(2) Notices of a right to claim a lien shall not be required of:
(a) Persons who contract directly with the owner or the owner’s common law agent;
(b) Laborers whose claim of lien is based solely on performing labor; or
(c) Subcontractors who contract for the improvement of real property directly with the prime contractor, except as provided in subsection (3)(b) of this section.
(3) Persons who furnish professional services, materials, or equipment in connection with the repair, alteration, or remodel of an existing owner occupied single-family residence or appurtenant garage:
(a) Who contract directly with the owner-occupier or their common law agent shall not be required to send a written notice of the right to claim a lien and shall have a lien for the full amount due under their contract, as provided in RCW 60.04.021; or
(b) Who do not contract directly with the owner-occupier or their common law agent shall give notice of the right to claim a lien to the owner occupier. Liens of persons furnishing professional services, materials, or equipment who do not contract directly with the owner-occupier or their common law agent may only be satisfied from amounts not yet paid to the prime contractor by the owner at the time the notice described in this section is received, regardless of whether amounts not yet paid to the prime contractor are due. For the purposes of this subsection
(4) The notice of right to claim a lien described in subsection (1) of this section, shall include but not be limited to the following information and shall substantially be in the following form, using lower-case and upper-case ten-point type where appropriate.
NOTICE TO OWNER
IMPORTANT: READ BOTH SIDES OF THIS NOTICE CAREFULLY. PROTECT YOURSELF FROM PAYING TWICE
Re: (description of property: Street address or general location.)
AT THE REQUEST OF: (Name of person ordering the professional services, materials, or equipment)
THIS IS NOT A LIEN: This notice is sent to you to tell you who is providing professional services, materials, or equipment for the improvement of your property and to advise you of the rights of these persons and your responsibilities. Also take note that laborers on your project may claim a lien without sending you a notice.
OWNER/OCCUPIER OF EXISTING RESIDENTIAL PROPERTY
Under Washington law, those who furnish labor, professional services, materials, or equipment for the repair, remodel, or alteration of your owner-occupied principal residence and who are not paid, have a right to enforce their claim for payment against your property. This claim is known as a construction lien.The law limits the amount that a lien claimant can claim against your property. Claims may only be made against that portion of the contract price you have not yet paid to your prime contractor as of the time this notice was given to you or three days after this notice was mailed to you. Review the back of this notice for more information and ways to avoid lien claims.
COMMERCIAL AND/OR NEW RESIDENTIAL PROPERTY
We have or will be providing professional services, materials, or equipment for the improvement of your commercial or new residential project. In the event you or your contractor fail to pay us, we may file a lien against your property. A lien may be claimed for all professional services, materials, or equipment furnished after a date that is sixty days before this notice was given to you or mailed to you, unless the improvement to your property is the construction of a new single-family residence, then ten days before this notice was given to you or mailed to you.
Brief description of professional services, materials, or equipment provided or to be provided: ________________
IMPORTANT INFORMATION ON REVERSE SIDE
IMPORTANT INFORMATION FOR YOUR PROTECTION
This notice is sent to inform you that we have or will provide professional services, materials, or equipment for the improvement of your property. We expect to be paid by the person who ordered our services, but if we are not paid, we have the right to enforce our claim by filing a construction lien against your property.LEARN more about the lien laws and the meaning of this notice by discussing them with your contractor, suppliers, Department of Labor and Industries, the firm sending you this notice, your lender, or your attorney.
COMMON METHODS TO AVOID CONSTRUCTION LIENS:
There are several methods available to protect your property from construction liens. The following are two of the more commonly used methods.
DUAL PAYCHECKS (Joint Checks):
When paying your contractor for services or materials, you may make checks payable jointly to the contractor and the firms furnishing you this notice.
You may require your contractor to provide lien releases signed by all the suppliers and subcontractors from whom you have received this notice. If they cannot obtain lien releases because you have not paid them, you may use the dual payee check method to protect yourself.
YOU SHOULD TAKE APPROPRIATE STEPS TO PROTECT YOUR PROPERTY FROM LIENS. YOUR PRIME CONTRACTOR AND YOUR CONSTRUCTION LENDER ARE REQUIRED BY LAW TO GIVE YOU WRITTEN INFORMATION ABOUT LIEN CLAIMS. IF YOU HAVE NOT RECEIVED IT, ASK THEM FOR IT.
* * * * * * * * * * * * *
(5) Every potential lien claimant providing professional services where no improvement as defined in RCW 60.04.011(5) (a) or (b) has been commenced, and the professional services provided are not visible from an inspection of the real property may record in the real property records of the county where the property is located a notice which shall contain the professional service provider’s name, address, telephone number, legal description of the property, the owner or reputed owner’s name, and the general nature of the professional services provided. If such notice is not recorded, the lien claimed shall be subordinate to the interest of any subsequent mortgagee and invalid as to the interest of any subsequent purchaser if the mortgagee or purchaser acts in good faith and for a valuable consideration acquires an interest in the property prior to the commencement of an improvement as defined in RCW 60.04.011(5) (a) or (b) without notice of the professional services being provided. The notice described in this subsection shall be substantially in the following form:
NOTICE OF FURNISHING PROFESSIONAL SERVICES
That on the (day) day of (month and year) , (name of provider) began providing professional services upon or for the improvement of real property legally described as follows:[Legal Description is mandatory]
The general nature of the professional services provided is______________________________
The owner or reputed owner of the real property is____________________________________
__________________(Name of Claimant)
__________________(City, State, Zip Code)
(6) A lien authorized by this chapter shall not be enforced unless the lien claimant has complied with the applicable provisions of this section.
RCW 60.04.035 Acts of Coercion-Application of Chapter 19.86 RCW
The legislature finds that acts of coercion or attempted coercion, including threats to withhold future contracts, made by a contractor
RCW 60.04.041 Contractor Registration
A contractor or subcontractor required to be registered under chapter 18.27 RCW or licensed under chapter 19.28 RCW, or otherwise required to be registered or licensed by law, shall be deemed the construction agent of the owner for the purposes of establishing the lien created by this chapter only if so registered or licensed. Persons dealing with contractors or subcontractors may rely, for the purposes of this section, upon a certificate of registration issued pursuant to chapter 18.27 RCW or license issued pursuant to chapter 19.28 RCW, or other certificate or license issued pursuant to law, covering the period when the labor, professional services, material, or equipment shall be furnished, and the lien rights shall not be lost by suspension or revocation of registration or license without their knowledge. No lien rights described in this chapter shall be lost or denied by virtue of the absence, suspension, or revocation of such registration or license with respect to any contractor or subcontractor not in immediate contractual privity with the lien claimant.
RCW 60.04.051 Property Subject to Lien
The lot, tract, or parcel of land which is improved is subject to a lien to the extent of the interest of the owner at whose instance, directly or through a common law or construction agent the labor, professional services, equipment, or materials were furnished, as the court deems appropriate for satisfaction of the lien. If, for any reason, the title or interest in the land upon which the improvement is situated cannot be subjected to the lien, the court in order to satisfy the lien may order the sale and removal of the improvement from the land which is subject to the lien.
RCW 60.04.061 Priority of Lien
The claim of lien created by this chapter upon any lot or parcel of land shall be prior to any lien, mortgage, deed of trust, or other encumbrance which attached to the land after or was unrecorded at the time of commencement of labor or professional services or first delivery of materials or equipment by the lien claimant.
RCW 60.04.071 Release of Lien Rights
Upon payment and acceptance of the amount due to the lien claimant and upon demand of the owner or the person making payment, the lien claimant shall immediately prepare and execute a release of all lien rights for which payment has been made, and deliver the release to the person making payment. In any suit to compel deliverance of the release thereafter in which the court determines the delay was unjustified, the court shall, in addition to ordering the deliverance of the release, award the costs of the action including reasonable attorneys’ fees and any damages.
RCW 60.04.081 Frivolous Claim-Procedure
(1) Any owner of real property subject to a recorded claim of lien under this chapter, or contractor, subcontractor, lender, or lien claimant who believes the claim of lien to be frivolous and made without reasonable cause, or clearly excessive may apply by motion to the superior court for the county where the property, or some part thereof is located, for an order directing the lien claimant to appear before the court at a time no earlier than six nor later than fifteen days following the date of service of the application and order on the lien claimant, and show cause, if any he or she has, why the relief requested should not be granted. The motion shall state the grounds upon which relief is asked, and shall be supported by the affidavit of the applicant or his or her attorney setting forth a concise statement of the facts upon which the motion is based.
(2) The order shall clearly state that if the lien claimant fails to appear at the time and place noted the lien shall be released, with prejudice, and that the lien claimant shall be ordered to pay the costs requested by the applicant including reasonable attorneys’ fees.(3) If no action to foreclose the lien claim has been filed, the clerk of the court shall assign a cause number to the application and obtain from the applicant a filing fee of thirty-five dollars. If an action has been filed to foreclose the lien claim, the application shall be made a part of that action.
(4) If, following a hearing on the matter, the court determines that the lien is frivolous and made without reasonable cause, or clearly excessive, the court shall issue an order releasing the lien if frivolous and made without reasonable cause, or reducing the lien if clearly excessive, and awarding costs and reasonable attorneys’ fees to the applicant to be paid by the lien claimant. If the court determines that the lien is not frivolous and was made with reasonable cause, and is not clearly excessive, the court shall issue an order so stating and awarding costs and reasonable attorneys’ fees to the lien claimant to be paid by the applicant.
(5) Proceedings under this section shall not affect other rights and remedies available to the parties under this chapter or otherwise.
RCW 60.04.091 Recording-Time-Contents of Lien
Every person claiming a lien under RCW 60.04.021 shall file for recording, in the county where the subject property is located, a notice of claim of lien not later than ninety days after the person has ceased to furnish labor, professional services, materials, or equipment or the last date on which employee benefit contributions were due. The notice of claim of lien:
(1) Shall state in substance and effect:
(a) The name, phone number, and address of the claimant;
(b) The first and last date on which the labor, professional services, materials, or equipment was furnished or employee benefit contributions were due;
(c) The name of the person indebted to the claimant;
(d) The street address, legal description, or other description reasonably calculated to identify, for a person familiar with the area, the location of the real property to be charged with the lien;
(e) The name of the owner or reputed owner of the property, if known, and, if not known, that fact shall be stated; and
(f) The principal amount for which the lien is claimed.
(2) Shall be signed by the claimant or some person authorized to act on his or her behalf who shall affirmatively state they have read the notice of claim of lien and believe the notice of claim of lien to be true and correct under penalty of perjury, and shall be acknowledged pursuant to chapter 64.08 RCW. If the lien has been assigned, the name of the assignee shall be stated. Where an action to foreclose the lien has been commenced such notice of claim of lien may be amended as pleadings may be by order of the court insofar as the interests of third parties are not adversely affected by such amendment. A claim of lien substantially in the following form shall be
CLAIM OF LIEN
Notice is hereby given that the person named below claims a lien pursuant to *chapter 64.04 RCW. In support of this lien the following information is submitted:
1. NAME OF LIEN CLAIMANT: ____________________________
TELEPHONE NUMBER: ____________________________________
2. DATE ON WHICH THE CLAIMANT BEGAN TO PERFORM LABOR, PROVIDE PROFESSIONAL SERVICES, SUPPLY MATERIAL OR EQUIPMENT OR THE DATE ON WHICH EMPLOYEE BENEFIT CONTRIBUTIONS BECAME DUE: ______________________________
3. NAME OF PERSON INDEBTED TO THE CLAIMANT:______________________________
4. DESCRIPTION OF THE PROPERTY AGAINST WHICH A LIEN IS CLAIMED (Street address, legal description or other information that will reasonably describe the property): ________________________________
5. NAME OF THE OWNER OR REPUTED OWNER (If not known state
6. THE LAST DATE ON WHICH LABOR WAS PERFORMED; PROFESSIONAL SERVICES WERE FURNISHED; CONTRIBUTIONS TO AN EMPLOYEE BENEFIT PLAN WERE DUE; OR MATERIAL, OR EQUIPMENT WAS FURNISHED: _______________________________________________
7. PRINCIPAL AMOUNT FOR WHICH THE LIEN IS CLAIMED IS: _______________________________
8. IF THE CLAIMANT IS THE ASSIGNEE OF THIS CLAIM SO STATE HERE: _____________________
(Phone number, address, city, and state of claimant)
STATE OF WASHINGTON,
COUNTY OF______________________, ss.
______________________, being sworn, says: I am the claimant (or attorney of the claimant, or administrator, representative, or agent of the trustees of an employee benefit plan) above named; I have read or heard the foregoing claim, read and know the contents thereof, and believe the same to be true and correct and that the claim of lien is not frivolous and is made with reasonable cause, and is not clearly excessive under penalty of perjury ________________
Subscribed and sworn to before me this _____ day of ____________________.
The period provided for recording the claim of lien is a period of limitation and no action to foreclose a lien shall be maintained unless the claim of lien is filed for recording within the ninety-day period stated. The lien claimant shall give a copy of the claim of lien to the owner or reputed owner by mailing it by certified or registered mail or by personal service within fourteen days of the time the claim of lien is filed for recording. Failure to do so results in a forfeiture of any right the claimant may have to attorneys’ fees and costs against the owner under RCW 60.04.181.[NOTES: Reviser’s note: The reference to chapter 64.04 RCW appears to be erroneous. Reference to chapter 60.04 RCW was apparently intended.]
RCW 60.04.101 Separate Residential Units-Time for Filing
When furnishing labor, professional services, materials, or equipment for the construction of two or more separate residential units, the time for filing claims of lien against each separate residential unit shall commence to run upon the cessation of the furnishing of labor, professional services, materials, or equipment on each residential unit, as provided in this chapter. For the purposes of this section a separate residential unit is defined as consisting of one residential structure together with any garages or other outbuildings appurtenant thereto.
RCW 60.04.111 Recording-Fees
The county auditor shall record the notice of claim of lien in the same manner as deeds and other instruments of title are recorded under chapter 65.08 RCW. Notices of claim of lien for registered land need not be recorded in the Torrens register. The county auditor shall charge no higher fee for recording notices of claim of lien than other documents.
RCW 60.04.121 Lien-Assignment
Any lien or right of lien created by this chapter and the right of action to recover therefore, shall be assignable so as to vest in the assignee all rights and remedies of the assignor, subject to all defenses thereto that might be made.
RCW 60.04.131 Claims-Designation of Amount Due
In every case in which the notice of claim of lien is recorded against two or more separate pieces of property owned by the same person or owned by two or more persons jointly or otherwise, who contracted for the labor, professional services, material, or equipment for which the notice of claim of lien is recorded, the person recording the notice of claim of lien shall designate in the notice of claim of lien the amount due on each piece of property, otherwise the lien is subordinated to other liens that may be established under this chapter. The lien of such claim does not extend beyond the amount designated as against other creditors having liens upon any of such pieces of property.
RCW 60.04.141 Lien-Duration-Procedural Limitations
No lien created by this chapter binds the property subject to the lien for a longer period than eight calendar months after the claim of lien
RCW 60.04.151 Rights of Owner-Recovery Options
The lien claimant shall be entitled to recover upon the claim recorded the contract price after deducting all claims of other lien claimants to whom the claimant is liable, for furnishing labor, professional services, materials, or equipment; and in all cases where a claim of lien shall be recorded under this chapter for labor, professional services, materials, or equipment supplied to any lien claimant, he or she shall defend any action brought thereupon at his or her own expense. During the pendency of the action, the owner may withhold from the prime contractor the amount of money for which a claim is recorded by any subcontractor, supplier, or laborer. In case of judgment against the owner or the owner’s property, upon the lien, the owner shall be entitled to deduct from sums due to the prime contractor the principal amount of the judgment from any amount due or to become due from the owner to the prime contractor plus such costs, including interest and attorneys’ fees, as the court deems just and equitable, and the owner shall be entitled to recover back from the prime contractor the amount for which a lien or liens are established in excess of any sum that may remain due from the owner to the prime contractor.
RCW 60.04.161 Bond in Lieu of Claim
Any owner of real property subject to a recorded claim of lien under this chapter, or contractor, subcontractor, lender, or lien claimant who disputes the correctness or validity of the claim of lien may record, either before or after the commencement of an action to enforce the lien, in the office of the county recorder or auditor in the county where the claim of lien was recorded, a bond issued by a surety company authorized to issue surety bonds in the state. The surety shall be listed in the latest federal department of the treasury list of surety companies acceptable on federal bonds, published in the Federal Register, as authorized to issue bonds on United States government projects with an underwriting limitation, including applicable reinsurance, equal to or greater than the amount of the bond to be recorded. The bond shall contain a description of the claim of lien and real property involved, and be in an amount equal to the greater of five thousand dollars or two times the amount of the lien claimed if it is ten thousand dollars or less, and in an amount equal to or greater than one and one-half times the amount of the lien if it is in excess of ten thousand dollars. If the claim of lien affects more than one parcel of real property and is segregated to each parcel, the bond may be segregated the same as in the claim of lien. A separate bond shall be required for each claim of lien made by separate claimants. However, a single bond may be used to guarantee payment of amounts claimed by more than one claim of lien by a single claimant so long as the amount of the bond meets the requirements of this section as applied to the aggregate sum of all claims by such claimant. The condition of the bond shall be to guarantee payment of any judgment upon the lien in favor of the lien claimant entered in any action to recover the amount claimed in a claim of lien, or on the claim asserted in the claim of lien. The effect of recording a bond shall be to release the real property described in the notice of claim of lien from the lien and any action brought to recover the amount claimed. Unless otherwise prohibited by law, if no action is commenced to recover on a lien within the time specified in RCW 60.04.141, the surety shall be discharged from liability under the bond. If an action is timely commenced, then on payment of any judgment entered in the action or on payment of the full amount of the bond to the holder of the judgment, whichever is less, the surety shall be discharged from liability under the bond.
Nothing in this section shall in any way prohibit or limit the use of other methods, devised by the affected parties to secure the obligation underlying a claim of lien and to obtain a release of real property from a claim of lien.
RCW 60.04.171 Foreclosure-Parties
The lien provided by this chapter, for which claims of lien have been recorded, may be foreclosed and enforced by a civil action in the court having jurisdiction in the manner prescribed for the judicial foreclosure of a mortgage. The court shall have the power to order the sale of the property. In any action brought to foreclose a lien, the owner shall be joined as a party. The interest in the real property of any person who, prior to the commencement of the action, has a recorded interest in the property, or any part thereof, shall not be foreclosed or affected unless they are joined as a party.
A person shall not begin an action to foreclose a lien upon any property while a prior action begun to foreclose another lien on the same property is pending, but if not made a party plaintiff or defendant to the prior action, he or she may apply to the court to be joined as a party thereto, and his or her lien may be foreclosed in the same action. The filing of such application shall toll the running of the period of limitation established by RCW 60.04.141 until disposition of the application or other time set by the court. The court shall grant the application for joinder unless to do so would create an undue delay or cause hardship which cannot be cured by the imposition of costs or other conditions as the court deems just. If a lien foreclosure action is filed during the pendency of another such action, the court may, on its own motion or the motion of any party, consolidate actions upon such terms and conditions as the court deems just, unless to do so would create an undue delay or cause hardship which cannot be cured by the imposition of costs or other conditions. If consolidation of actions is not permissible under this section, the lien foreclosure action filed during the pendency of another such action shall not be dismissed if the filing was the result of mistake, inadvertence, surprise, excusable neglect, or irregularity. An action to foreclose a lien shall not be dismissed at the instance of a plaintiff therein to the prejudice of another party to the suit who claims a lien.
RCW 60.04.181 Rank of Lien-Application of Proceeds-Attorneys’ Fees
(1) In every case in which different construction liens are claimed against the same property, the court shall declare the rank of such lien or class of liens, which liens shall be in the following order:
(a) Liens for the performance of labor;
(b) Liens for contributions owed to employee benefit plans;
(c) Liens for furnishing material, supplies, or equipment;
(d) Liens for subcontractors, including but not limited to their labor and materials; and
(e) Liens for prime contractors, or for professional services.
(2) The proceeds of the sale of property must be applied to each lien or class of liens in order of its rank and, in an action brought to foreclose a lien, pro rata among each claimant in each separate priority class. A personal judgment may be rendered against any party personally liable for any debt for which the lien is claimed. If the lien is established, the judgment shall provide for the enforcement thereof upon the property liable as in the case of foreclosure of judgment liens. The amount realized by such enforcement of the lien shall be credited upon the proper personal judgment. The deficiency, if any, remaining unsatisfied, shall stand as a personal judgment, and may be collected by execution against any party liable therefore.
(3) The court may allow the prevailing party in the action, whether plaintiff or defendant, as part of the costs of the action, the moneys paid for recording the claim of lien, costs of title report, bond costs, and attorneys’ fees and necessary expenses incurred by the attorney in the superior court, court of appeals, supreme court, or arbitration, as the court or arbitrator deems reasonable. Such costs shall have the priority of the class of lien to which they are related, as established by subsection (1) of this section.
(4) Real property against which a lien under this chapter is enforced may be ordered sold by the court and the proceeds deposited into the registry of the clerk of the court, pending further determination respecting distribution of the proceeds of the sale.
RCW 60.04.190 Destruction or Concealment of Property-Removal From Premises-Penalty
See RCW 61.12.030, 9.45.060.
RCW 60.04.191 Effect of Note-Personal Action Preserved
The taking of a promissory note or other evidence of indebtedness for any labor, professional services, material, or equipment furnished for which a lien is created by this chapter does not discharge the lien therefore, unless expressly received as payment and so specified therein. Nothing in this chapter shall be construed to impair or affect the right of any person to whom any debt may be due for the furnishing of labor, professional services, material, or equipment to maintain a personal action to recover the debt against any person liable therefore.
RCW 60.04.201 Material Exempt from Process-Exception
Whenever material is furnished for use in the improvement of property subject to a lien created by this chapter, the material is not subject
RCW 60.04.211 Lien-Effect on Community Interest
The claim of lien, when filed as required by this chapter, shall be notice to the husband or wife of the person who appears of record to be the owner of the property sought to be charged with the lien, and shall subject all the community interest of both husband and wife to the lien.
RCW 60.04.221 Notice to Lender-Withholding of Funds
Any lender providing interim or construction financing where there is not a payment bond of at least fifty percent of the amount of construction financing shall observe the following procedures and the rights and liabilities of the lender and potential lien claimant shall be affected as follows:
(1) Any potential lien claimant who has not received a payment within five days after the date required by their contract, invoice, employee benefit plan agreement, or purchase order may within thirty-five days of the date required for payment of the contract, invoice, employee benefit plan agreement, or purchase order, give a notice as provided in subsections (2) and(3) of this section of the sums due and to become due, for which a potential lien claimant may claim a lien under this chapter.
(2) The notice shall be signed by the potential lien claimant or some person authorized to act on his or her behalf.
(3) The notice shall be given in writing to the lender at the office administering the interim or construction financing, with a copy given to the owner and appropriate prime contractor. The notice shall be given by:
(a) Mailing the notice by certified or registered mail to the lender, owner, and appropriate prime contractor; or
(b) Delivering or serving the notice personally and obtaining evidence of delivery in the form of a receipt or other acknowledgment signed by the lender, owner, and appropriate prime contractor, or an affidavit of service.
(4) The notice shall state in substance and effect as follows:
(a) The person, firm, trustee, or corporation filing the notice is entitled to receive contributions to any type of employee benefit plan or has furnished labor, professional services, materials, or equipment for which a lien is given by this chapter. (b) The name of the prime contractor, common law agent, or construction agent ordering the same.
(c) A common or street address of the real property being improved or the legal description of the real property.
(d) The name, business address, and telephone number of the lien claimant.
The notice to the lender may contain additional information but shall be in substantially the following form:
NOTICE TO REAL PROPERTY LENDER
(Authorized by RCW _____)
TO: ___________________________(Name of Lender)
_______________________________(Administrative Office-Street Address)
AND TO: _______________________(Owner)
AND TO: _______________________(Prime Contractor-If Different Than Owner)
_______________________________(Name of Laborer, Professional,Materials, or Equipment Supplier) whose business address is_______, did at the property located at __________________________________________________
(Check appropriate box) ( ) perform labor () furnish professional services ( ) provide materials ( ) supply equipment as follows:
which was ordered by _______________________(Name of Person)
whose address was stated to be _____________________________
The amount owing to the undersigned according to contract or purchase order for labor, supplies, or equipment (as above mentioned) is the sum
You are hereby required to withhold from any future draws on existing construction financing which has beenmade on the subject property (to the extent there remain undisbursed funds) the sum of ___________ Dollars($_________ ).
Failure to comply with the requirements of this notice may subject the lender to a whole or partial compromise of any priority lien interest it may have pursuant to RCW 60.04.226.
(5) After the receipt of the notice, the lender shall withhold from the next and subsequent draws the amount claimed to be due as stated in the notice. Alternatively, the lender may obtain from the prime contractor or borrower a payment bond for the benefit of the potential lien claimant in an amount sufficient to cover the amount stated in the potential lien claimant’s notice. The lender shall be obligated to withhold amounts only to the extent that sufficient interim or construction financing funds remain undisbursed as of the date the lender receives the notice.
(6) Sums so withheld shall not be disbursed by the lender, except by the written agreement of the potential lien claimant, owner, and prime contractor in such form as may be prescribed by the lender, or the order of a court of competent jurisdiction.
(7) In the event a lender fails to abide by the provisions of *subsections (4) and (5) of this section, then the mortgage, deed of trust, or other encumbrance securing the lender shall be subordinated to the lien of the potential lien claimant to the extent of the interim or construction financing wrongfully disbursed, but in no event more than the amount stated in the notice plus costs as fixed by the court, including reasonable attorneys’ fees.
(8) Any potential lien claimant shall be liable for any loss, cost, or expense, including reasonable attorneys’ fees and statutory costs, to a party injured thereby arising out of any unjust, excessive, or premature notice filed under purported authority of this section.
(9)(a) Any owner of real property subject to a notice to real property lender under this section, or the contractor, subcontractor, lender, or lien claimant who believes the claim that underlies the notice is frivolous and made without reasonable cause, or is clearly excessive may apply by motion to the superior court for the county where the property, or some part thereof is located, for an order commanding the potential lien claimant who issued the notice to the real property lender to appear before the court at a time no earlier than six nor later than fifteen days from the date of service of the application and order on the potential lien claimant, and show cause, if any he or she has, why the notice to real property lender should not be declared void. The motion shall state the grounds upon which relief is asked and shall be supported by the affidavit of the applicant or his or her attorney setting forth a concise statement of the facts upon which the motion is based.
(b) The order shall clearly state that if the potential lien claimant fails to appear at the time and place noted, the notice to lender shall be declared void and that the potential lien claimant issuing the notice shall be ordered to pay the costs requested by the applicant including reasonable attorneys’ fees.
(c) The clerk of the court shall assign a cause number to the application and obtain from the applicant a filing fee of thirty-five dollars.
(d) If, following a hearing on the matter, the court determines that the claim upon which the notice to real property lender is based is frivolous and made without reasonable cause, or clearly excessive, the court shall issue an order declaring the notice to real property lender void if frivolous and made without reasonable cause, or reducing the amount stated in the notice if clearly excessive, and awarding costs and reasonable attorneys’ fees to the applicant to be paid by the person who issued the notice. If the court determines that the claim underlying the notice to real property lender is not frivolous and was made with reasonable cause, and is not clearly excessive, the court shall issue an order so stating and awarding costs and reasonable attorneys’ fees to the issuer of the notice to be paid by the applicant.
(e) Proceedings under this subsection shall not affect other rights and remedies available to the parties under this chapter or otherwise.[NOTES: Reviser’s note: The reference to subsections (4) and (5) of this section appears to be erroneous. Engrossed Senate Bill No. 6441 changed the subsection numbers. Subsections (4) and (5) are now subsections (5) and (6).]
RCW 60.04.226 Financial Encumbrances-Priorities
Except as otherwise provided in RCW 60.04.061 or 60.04.221, any mortgage or deed of trust shall be prior to all liens, mortgages, deeds of trust, and other encumbrances which have not been recorded prior to the recording of the mortgage or deed of trust to the extent of all sums secured by the mortgage or deed of trust regardless of when the same are disbursed or whether the disbursements are obligatory.
RCW 60.04.230 Construction Projects-Notice to be Posted by Prime Contractor-Penalty
(1) For any construction project costing more than five thousand dollars the prime contractor shall post in plain view for the duration of the construction project a legible notice at the construction job site containing the following:
(a) The legal description, or the tax parcel number assigned pursuant to RCW 84.40.160, and the street address if available, and may include any other identification of the construction site by the prime contractor;
(b) The property owner’s name, address, and phone number;
(c) The prime contractor’s business name, address, phone number, current state contractor registration number and identification; and
(i) The name, address, and phone number of the office of the lender administering the interim construction financing, if any; or
(ii) The name and address of the firm that has issued a payment bond, if any, on behalf of the prime contractor for the protection of the owner if the bond is for an amount not less than fifty percent of the total amount of the construction project.
(2) For any construction project which requires a building permit under local ordinance, compliance with the posting requirements of RCW 19.27.095 shall constitute compliance with this section. Otherwise, the information shall be posted as set forth in this section.
(3) Failure to comply with this section shall subject the prime contractor to a civil penalty of not more than five thousand dollars, payable
RCW 60.04.250 Informational Materials on Construction Lien Laws-Master Documents
The department of labor and industries shall prepare master documents that provide informational material about construction lien laws and available safeguards against real property lien claims. The material shall include methods of protection against lien claims, including obtaining lien release documents, performance bonds, joint payee checks, the opportunity to require contractor disclosure of all potential lien claimants as a condition of payment, and lender supervision under *RCW 60.04.200 and 60.04.210. The material shall also include sources of further information, including the department of labor and industries and the office of the attorney general.[NOTES: Reviser’s note: RCW 60.04.200 and 60.04.210 were repealed by 1991 c 281 § 31, effective April 1, 1992.]
RCW 60.04.255 Informational Materials on Construction Lien Laws-Copies-Liability
(1) Every real property lender shall provide a copy of the informational material described in RCW 60.04.250 to all persons obtaining loans, the proceeds of which are to be used for residential construction or residential repair or remodeling.
(2) Every contractor shall provide a copy of the informational material described in RCW 60.04.250 to customers required to receive contractor disclosure notice under RCW 18.27.114.
(3) No cause of action may lie against the state, a real property lender, or a contractor arising from the provisions of RCW 60.04.250 and this section.
(4) For the purpose of this section,
RCW 60.04.261 Availability of Information
The prime contractor shall immediately supply the information listed in RCW 19.27.095(2) to any person who has contracted to supply materials,
RCW 60.04.900 Liberal Construction-1991 c 281
RCW 19.27.095, 60.04.230, and 60.04.011 through 60.04.226 and 60.04.261 are to be liberally construed to provide security for all parties intended to be protected by their provisions.
RCW 60.04.901 Captions Not Law-1991 c 281
Section headings as used in this chapter do not constitute any part of the law.
RCW 60.04.902 Effective Date, Application-1991 c 281
This act shall take effect June 1, 1992. Lien claims based on an improvement commenced by a potential lien claimant on or after June 1, 1992, shall be governed by the provisions of this act.
RCW 60.04.903 Effective Date-1992 c 126
This act is necessary for the immediate preservation of the public peace, health, or safety, or support of the state government and its existing public institutions, and shall take effect June 1, 1992, except section 14 of this act which shall take effect immediately [March 31, 1992].
RCW 60.04.904 Application of Chapter 281, Laws of 1991, To Actions Pending as of June 1, 1992-1993 c 357
All rights acquired and liabilities incurred under acts or parts of act repealed by chapter 281, Laws of 1991, are hereby preserved, and all actions pending as of June 1, 1992, shall proceed under the law as it existed at the time chapter 281, Laws of 1991, took effect.[NOTES: Retroactive application-1993 c 357:
Effective date-1993 c 357: